TERMS OF TRADE

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

1. Definitions

1.1  “Contract” means the terms and conditions contained herein, together with any Quotation, order, invoice or other document or amendments expressed to be supplemental to this Contract.

1.2  “SCJ” means Streamline Cabinets & Joinery Pty Ltd ATF Biggs Family Trust T/A Streamline Cabinets & Joinery Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of Streamline Cabinets & Joinery Pty Ltd ATF Biggs Family Trust T/A Streamline Cabinets & Joinery Pty Ltd.

1.3  “Client” means the person/s, entities or any person acting on behalf of and with the authority of the Client requesting SCJ to provide the Works as specified in any proposal, quotation, order, invoice or other documentation, and:
(a) if there is more than one Client, is a reference to each Client jointly and severally; and

(b) if the Client is a partnership, it shall bind each partner jointly and severally; and

(c) if the Client is a part of a Trust, shall be bound in their capacity as a trustee; and

(d) includes the Client’s executors, administrators, successors and permitted assigns.

1.4  “Works” means all Works (including consultation, manufacturing and/or installation services) or Materials supplied by SCJ to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).

1.5  "Confidential Information” means information of a confidential nature whether oral, written or in electronic form including, but not limited to, this Contract, either party’s intellectual property, operational information, know-how, trade secrets, financial and commercial affairs, contracts, client information (including but not limited to, “Personal Information” such as: name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) and pricing details.

1.6  “Cookies” means small files which are stored on a user’s computer. They are designed to hold a modest amount of data (including Personal Information) specific to a particular client and website, and can be accessed either by the web server or the client’s computer. If the Client does not wish to allow Cookies to operate in the background when ordering from the website, then the Client shall have the right to enable / disable the Cookies first by selecting the option to enable / disable provided on the website, prior to ordering Works via the website.

1.7  “Price” means the Price payable (plus any GST where applicable) for the Works as agreed between SCJ and the Client in accordance with clause 5 below.

1.8  “GST” means Goods and Services Tax as defined within the “A New Tax System (Goods and Services Tax) Act 1999” (Cth).

2. Acceptance

2.1  The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of any Works.

2.2  In the event of any inconsistency between the terms and conditions of this Contract and any other prior document or schedule that the parties have entered into, the terms of this Contract shall prevail.

2.3  Any amendment to the terms and conditions contained in this Contract may only be amended in writing by the consent of both parties.

2.4 The Client acknowledges and accepts that:

(a)  the supply of Works on credit shall not take effect until the Client has completed a credit application with SCJ and it has been approved with a credit limit established for the account; and

(b)  in the event that the supply of Works request exceeds the Client’s credit limit and/or the account exceeds the payment terms, SCJ reserves the right to refuse delivery; and

(c)  the supply of Materials for accepted orders may be subject to availability and if, for any reason, Materials are not or cease to be available, SCJ reserves the right to substitute comparable Materials (or components of the Materials) and vary the Price as per clause 5.2. In all such cases SCJ will notify the Client in advance of any such substitution, and also reserves the right to place the Client’s orderand/or Works on hold, as per clause 6.2 until such time as SCJ and the Client agree to such changes.

2.5  Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 14 of the Electronic Transactions (Queensland) Act 2001 or any other applicable provisions of that Act or any Regulations referred to in that Act.

3. Errors and Omissions

3.1  The Client acknowledges and accepts that SCJ shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):

(a) resulting from an inadvertent mistake made by SCJ in the formation and/or administration of this Contract; and/or

(b) contained in/omitted from any literature (hard copy and/or electronic) supplied by SCJ in respect of the Works.

3.2  In the event such an error and/or omission occurs in accordance with clause 3.1, and is not attributable to the negligence and/or wilful misconduct of SCJ; the Client shall not be entitled to treat this Contract as repudiated nor render it invalid.

4. Change in Control

4.1 The Client shall give SCJ not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s,change of trustees, or business practice). The Client shall be liable for any loss incurred by SCJ as a result of the Client’s failure to complywith this clause.

5. Price and Payment

5.1  At SCJ’s sole discretion the Price shall be either:

(a)  as indicated on invoices provided by SCJ to the Client in respect of Works performed or Materials supplied; or

(b)  SCJ’s quoted Price (subject to clause 5.2) which shall be binding upon SCJ provided that the Client shall accept SCJ’s quotation in writing within thirty (30) days.

5.2  SCJ reserves the right to change the Price:

(a) if a variation to the Materials which are to be supplied is requested; or

(b)  if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or

(c)  where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to accessing the site, obscured site defects which require remedial work, health hazards and safety considerations (such as the discovery of asbestos) or prerequisite work by any third party not being completed, change of plans, hidden pipes and wiring in walls etc.) which are only discovered on commencement of the Works; or

(d)  in the event of increases to SCJ in the cost of labour or Materials (including, but not limited to, any variation as a result of fluctuations in currency exchange rates or increases to SCJ in the cost of taxes, levies, freight and insurance charges or delays in shipment etc.) which are beyond SCJ’s control.

5.3  Variations will be charged for on the basis of SCJ’s quotation, and will be detailed in writing, and shown as variations on SCJ’s invoice. The Client shall be required to respond to any variation submitted by SCJ within ten (10) working days. Failure to do so will entitle SCJ to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.

5.4  At SCJ’s sole discretion a deposit may be required.

5.5  Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by SCJ, which may be:

(a)  on completion of the Works; or

(b)  before commencement of the Works; or

(c)  by way of progress payments in accordance with SCJ’s specified progress payment schedule. Such progress payment claims may

include the reasonable value of authorised variations and the value of any Materials delivered to the site but not yet installed; or

(d)  for certain approved Clients, due thirty (30) days following:

(i) the end of the month in which a statement is posted to the Client’s address or address for notices;

(ii) the date specified on any invoice or other form as being the date for payment; or

  1. (e)  the date specified on any invoice or other form as being the date for payment; or

  2. (f)  failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by SCJ.

  1. 5.6  Payment may be made by cash, cheque, bank cheque, electronic/on-line banking, credit card (a surcharge may apply per transaction), or by any other method as agreed to between the Client and SCJ.

  2. 5.7  SCJ may in its discretion allocate any payment received from the Client towards any invoice that SCJ determines and may do so at the time of receipt or at any time afterwards. On any default by the Client SCJ may re-allocate any payments previously received and allocated. In the absence of any payment allocation by SCJ, payment will be deemed to be allocated in such manner as preserves the maximum value of SCJ’s Purchase Money Security Interest (as defined in the PPSA) in the Materials.

  3. 5.8  The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by SCJ nor to withhold payment of any invoice because part of that invoice is in dispute.

  4. 5.9  Unless otherwise stated the Price does not include GST. In addition to the Price, the Client must pay to SCJ an amount equal to any GST SCJ must pay for any supply by SCJ under this or any other contract for the sale of the Materials. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition, the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

6. Provision of the Works

  1. 6.1  Subject to clause 6.2 it is SCJ’s responsibility to ensure that the Works start as soon as it is reasonably possible.

  2. 6.2  The Works’ commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that SCJ claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond SCJ’s control, including but

    not limited to any failure by the Client to: (a) make a selection; or
    (b) have the site ready for the Works; or (c) notify SCJ that the site is ready.

  3. 6.3  At SCJ’s sole discretion, the cost of delivery is included in the Price.

  4. 6.4  SCJ may deliver the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions

    in these terms and conditions.

  5. 6.5  Any time specified by SCJ for delivery of the Works is an estimate only and SCJ will not be liable for any loss or damage incurred by the

    Client as a result of delivery being late. However both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that SCJ is unable to supply the Works as agreed solely due to any action or inaction of the Client, then SCJ shall be entitled to charge a reasonable fee for re-supplying the Works at a later time and date, and/or for storage of the Materials.

7. Risk

7.1 If SCJ retains ownership of the Materials under clause 12 then:
(a) where SCJ is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must

insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that the Materials are delivered by SCJ or SCJ’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address).

(b) where SCJ is to both supply and install Materials then SCJ shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Client.

  1. 7.2  Notwithstanding the provisions of clause 7.1 if the Client specifically requests SCJ to leave Materials outside SCJ’s premises for collection orto deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’sresponsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.

  2. 7.3  The Client warrants that any structures to which the Materials are to be affixed are able to withstand the installation thereof and are of suitable capacity to handle the Materials once installed. If for any reason (including the discovery of asbestos, defective or unsafe structures

#29014 © Copyright – EC Credit Control 1999 - 2019

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

or risk) that SCJ reasonably form the opinion that the Client’s premises is not safe for the Works to proceed then SCJ shall be entitled to

delay the provision of the Works (in accordance with clause 6.2) until SCJ is satisfied that it is safe for the installation.

  1. 7.4  In the event asbestos or any other toxic substances are discovered at the site, that it is the Client’s responsibility to ensure the safe removal of the same. The Client further agrees to indemnify SCJ against any costs incurred by SCJ as a consequence of such discovery. Under no

    circumstances will SCJ handle removal of asbestos product.

  2. 7.5  Where the Client has supplied materials for SCJ to complete the Works, the Client acknowledges that they accept responsibility for the

    suitability of purpose, quality and any faults inherent in the materials and warrants that those materials are up acceptably industry standards. SCJ shall not be responsible for any defects in the materials, any loss or damage to the materials (or any part thereof), howsoever arising from the use of materials supplied by the Client.

  3. 7.6  Where the Client requests the re-use of existing materials or the supply of third-party materials (including, but not limited to, granite or stainless steel bench tops, appliances, and/or sinks), no responsibility shall be taken by SCJ for the appearance, service or performance of the materials.

  4. 7.7  Granite and marble caesarstone, being stone products that have natural colour and shade tones, markings, and veining may vary from colour samples provided. SCJ gives no guarantee (expressed or implied) that colour samples will match the Materials supplied. SCJ will make every effort to match colour samples to the Materials supplied but will not be liable in any way whatsoever for colour samples differing from the Materials supplied.

  5. 7.8  Marble and Granite being porous products, therefore, all products supplied by SCJ are sealed for protection. However, oil and other acidic substances are prone to causing discolouration and staining if left on surfaces for some time. The Client agrees to indemnify SCJ against any damage occurring after delivery and installation.

  6. 7.9  The Client acknowledges that Materials (including, but not limited to paint, timber, vinyl and acrylic, tiles, etc.) supplied may exhibit variations in shade tone, colour, texture, markings, veining, surface and finish, and may fade or change colour over time. SCJ will make every effort to match batches/samples of the Materials supplied in order to minimise such variations, but shall not be liable in any way whatsoever where such variations occur.

  7. 7.10  The Client also acknowledges that Materials supplied may:
    (a) expand, contract or distort as a result of exposure to heat, cold, weather; and (b) mark or stain if exposed to certain substances; and
    (c) be damaged or disfigured by impact or scratching.

8. Accuracy of Client’s Plans & Measurements for Orders

  1. 8.1  SCJ shall be entitled to rely on the accuracy of any plans, specifications (including CAD drawings) and other information provided by the Client. The Client acknowledges and agrees that in the event that any of this information provided by the Client is inaccurate, SCJ accepts no responsibility for any loss, damages, or costs however resulting from these inaccurate plans, specifications or other information.

  2. 8.2  In the event the Client gives information relating to measurements and quantities of Materials required in completing the Works, it is theClient’s responsibility to verify the accuracy of the measurements and quantities, before the Client or Contractor places an order based on these measurements and quantities. SCJ accepts no responsibility for any loss, damages, or costs however resulting from the Client’s failureto comply with this clause.

9. Access

9.1 The Client shall ensure that SCJ has clear and free access to the site at all times to enable them to undertake the Works. SCJ shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of SCJ.

10. Hidden Works

  1. 10.1  Prior to SCJ commencing any work the Client must advise SCJ of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

  2. 10.2  Whilst SCJ will take all care to avoid damage to any underground services the Client agrees to indemnify SCJ in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 10.2.

11. Compliance with Laws

  1. 11.1  The Client and SCJ shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works.

  2. 11.2  The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the Works.

  3. 11.3  The Client agrees that the site will comply with any work health and safety (WHS) laws relating to building/construction sites and any other

    relevant safety standards or legislation.

12. Title

  1. 12.1  SCJ and the Client agree that ownership of the Materials shall not pass until: (a) the Client has paid SCJ all amounts owing to SCJ; and
    (b) the Client has met all of its other obligations to SCJ.

  2. 12.2  Receipt by SCJ of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.

  3. 12.3  It is further agreed that until ownership of the Materials passes to the Client in accordance with clause 12.1:

    1. (a)  the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to SCJ on request;

    2. (b)  the Client holds the benefit of the Client’s insurance of the Materials on trust for SCJ and must pay to SCJ the proceeds of any insurance

in the event of the Materials being lost, damaged or destroyed;

#29014 © Copyright – EC Credit Control 1999 - 2019

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

(c) the production of these terms and conditions by SCJ shall be sufficient evidence of SCJ’s rights to receive the insurance proceeds directfrom the insurer without the need for any person dealing with SCJ to make further enquiries;

  1. (d)  the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for SCJ and must pay or deliver the proceeds to SCJ on demand;

  2. (e)  the Client should not convert or process the Materials or intermix them with other goods but if the Client does so then the Client holds the resulting product on trust for the benefit of SCJ and must sell, dispose of or return the resulting product to SCJ as it so directs;

  3. (f)  unless the Materials have become fixtures the Client irrevocably authorises SCJ to enter any premises where SCJ believes the Materials are kept and recover possession of the Materials;

  4. (g)  SCJ may recover possession of any Materials in transit whether or not delivery has occurred;

  5. (h)  the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials

    while they remain the property of SCJ;

  6. (i)  SCJ may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not

    passed to the Client.

13. Personal Property Securities Act 2009 (“PPSA”)

  1. 13.1  In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPSA.

  2. 13.2  Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials and/or collateral (account) – being a monetary obligation of the Client to SCJ for Works – that have previously been supplied and that will be supplied in the future by SCJ to the Client.

  3. 13.3  The Client undertakes to:

    1. (a)  promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in

      all respects) which SCJ may reasonably require to:
      (i) register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities

      Register;
      (ii) register any other document required to be registered by the PPSA; or
      (iii) correct a defect in a statement referred to in clause 13.3(a)(i) or 13.3(a)(ii);

    2. (b)  indemnify, and upon demand reimburse, SCJ for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials charged thereby;

    3. (c)  not register a financing change statement in respect of a security interest without the prior written consent of SCJ;

    4. (d)  not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials and/or collateral

      (account) in favour of a third party without the prior written consent of SCJ;

    5. (e)  immediately advise SCJ of any material change in its business practices of selling the Materials which would result in a change in the

      nature of proceeds derived from such sales.

  4. 13.4  SCJ and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and

    conditions.

  5. 13.5  The Client hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.

  6. 13.6  The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.

  7. 13.7  Unless otherwise agreed to in writing by SCJ, the Client waives its right to receive a verification statement in accordance with section 157 of

    the PPSA.

  8. 13.8  The Client shall unconditionally ratify any actions taken by SCJ under clauses 13.3 to 13.5.

  9. 13.9  Subject to any express provisions to the contrary (including those contained in this clause 13), nothing in these terms and conditions is

    intended to have the effect of contracting out of any of the provisions of the PPSA.

14. Security and Charge

  1. 14.1  In consideration of SCJ agreeing to supply the Materials, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).

  2. 14.2  The Client indemnifies SCJ from and against all SCJ’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising SCJ’s rights under this clause.

  3. 14.3  The Client irrevocably appoints SCJ and each director of SCJ as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 14 including, but not limited to, signing any document on the Client’s behalf.

15. Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)

  1. 15.1  The Client must inspect all Materials on delivery (or the Works on completion) and must within fourteen (14) days of delivery notify SCJ in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow SCJ to inspect the Materials or to review the Works provided.

  2. 15.2  Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non- Excluded Guarantees).

  3. 15.3  SCJ acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.

  4. 15.4  Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, SCJ makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. SCJ’s liability in

respect of these warranties is limited to the fullest extent permitted by law.

#29014 © Copyright – EC Credit Control 1999 - 2019

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

  1. 15.5  If the Client is a consumer within the meaning of the CCA, SCJ’s liability is limited to the extent permitted by section 64A of Schedule 2.

  2. 15.6  If SCJ is required to replace any Materials under this clause or the CCA, but is unable to do so, SCJ may refund any money the Client has

    paid for the Materials.

  3. 15.7  If SCJ is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then

    SCJ may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account the value of

    Works and Materials which have been provided to the Client which were not defective.

  4. 15.8  If the Client is not a consumer within the meaning of the CCA, SCJ’s liability for any defect or damage in the Materials is:

    (a) limited to the value of any express warranty or warranty card provided to the Client by SCJ at SCJ’s sole discretion;(b) limited to any warranty to which SCJ is entitled, if SCJ did not manufacture the Materials;
    (c) otherwise negated absolutely.

  5. 15.9  Subject to this clause 15, returns will only be accepted provided that:
    (a) the Client has complied with the provisions of clause 15.1; and
    (b) SCJ has agreed that the Materials are defective; and
    (c) the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and(d) the Materials are returned in as close a condition to that in which they were delivered as is possible.

  6. 15.10  Notwithstanding clauses 15.1 to 15.9 but subject to the CCA, SCJ shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:

    1. (a)  the Client failing to properly maintain or store any Materials;

    2. (b)  the Client using the Materials for any purpose other than that for which they were designed;

    3. (c)  the Client continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;

    4. (d)  interference with the Works by the Client or any third party without SCJ’s prior approval;

    5. (e)  the Client failing to follow any instructions or guidelines provided by SCJ;

    6. (f)  fair wear and tear, any accident, or act of God.

  7. 15.11  SCJ may in its absolute discretion accept non-defective Materials for return in which case SCJ may require the Client to pay handling fees of up to ten percent (10%) of the value of the returned Materials plus any freight costs.

  8. 15.12  Notwithstanding anything contained in this clause if SCJ is required by a law to accept a return then SCJ will only accept a return on the conditions imposed by that law.

  9. 15.13  Subject to clause 15.1, customised, or non-stocklist items or Materials made or ordered to the Client’s specifications are not acceptable forcredit or return.

16. Intellectual Property

  1. 16.1  Where SCJ has designed, drawn, written plans or a schedule of Works, or created any products for the Client, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in SCJ, and shall only be used by the Client at SCJ’sdiscretion. Under no circumstances may such designs, drawings and documents be used without the express written approval of SCJ.

  2. 16.2  The Client warrants that all designs, specifications or instructions given to SCJ will not cause SCJ to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify SCJ against any action taken by a third party against SCJ in respect of any such infringement.

  3. 16.3  The Client agrees that SCJ may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which SCJ has created for the Client.

17. Default and Consequences of Default

  1. 17.1  Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at SCJ’s sole discretion such interest shall compound monthly at such a rate) after as well asbefore any judgment.

  2. 17.2  If the Client owes SCJ any money the Client shall indemnify SCJ from and against all costs and disbursements incurred by SCJ in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, SCJ’s contract default fee, and bank dishonour fees).

  3. 17.3  Further to any other rights or remedies SCJ may have under this Contract, if a Client has made payment to SCJ, and the transaction is subsequently reversed, the Client shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by SCJ under this clause 17 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Client’s obligationsunder this Contract.

  4. 17.4  Without prejudice to SCJ’s other remedies at law SCJ shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to SCJ shall, whether or not due for payment, become immediately payable if:

    1. (a)  any money payable to SCJ becomes overdue, or in SCJ’s opinion the Client will be unable to make a payment when it falls due;

    2. (b)  the Client has exceeded any applicable credit limit provided by SCJ;

    3. (c)  the Client becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or

    4. (d)  a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

18. Cancellation

  1. 18.1  Without prejudice to any other remedies SCJ may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions SCJ may suspend or terminate the supply of Works to the Client. SCJ will not be liable to the Client for any loss or damage the Client suffers because SCJ has exercised its rights under this clause.

  2. 18.2  SCJ may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Client. On giving such notice SCJ shall repay to the Client any sums paid in respect of the Price,

#29014 © Copyright – EC Credit Control 1999 - 2019

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

less any amounts owing by the Client to SCJ for Works already performed. SCJ shall not be liable for any loss or damage whatsoever

arising from such cancellation.

  1. 18.3  In the event that the Client cancels the delivery of Works the Client shall be liable for any and all loss incurred (whether direct or indirect) by

    SCJ as a direct result of the cancellation (including, but not limited to, any loss of profits).

  2. 18.4  Cancellation of orders for products made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once

    production has commenced, or an order has been placed.

19. Privacy Policy

  1. 19.1  All emails, documents, images or other recorded information held or used by SCJ is Personal Information, as defined and referred to in clause 19.3, and therefore considered Confidential Information. SCJ acknowledges its obligation in relation to the handling, use, disclosure and processing of Personal Information pursuant to the Privacy Act 1988 (“the Act”) including the Part IIIC of the Act being PrivacyAmendment (Notifiable Data Breaches) Act 2017 (NDB) and any statutory requirements, where relevant in a European Economic Area(“EEA”), under the EU Data Privacy Laws (including the General Data Protection Regulation “GDPR”) (collectively, “EU Data Privacy Laws”).SCJ acknowledges that in the event it becomes aware of any data breaches and/or disclosure of the Clients Personal Information, held by SCJ that may result in serious harm to the Client, SCJ will notify the Client in accordance with the Act and/or the GDPR. Any release of such Personal Information must be in accordance with the Act and the GDPR (where relevant) and must be approved by the Client by written consent, unless subject to an operation of law.

  2. 19.2  Notwithstanding clause 19.1, privacy limitations will extend to SCJ in respect of Cookies where transactions for purchases/orders transpire directly from SCJ’s website. SCJ agrees to display reference to such Cookies and/or similar tracking technologies, such as pixels and webbeacons (if applicable), such technology allows the collection of Personal Information such as the Client’s:

    1. (a)  IP address, browser, email client type and other similar details;

    2. (b)  tracking website usage and traffic; and

    3. (c)  reports are available to SCJ when SCJ sends an email to the Client, so SCJ may collect and review that information (“collectively

      Personal Information”)

    In order to enable / disable the collection of Personal Information by way of Cookies, the Client shall have the right to enable / disable the Cookies first by selecting the option to enable / disable, provided on the website prior to proceeding with a purchase/order via SCJ’s website.

  3. 19.3  The Client agrees for SCJ to obtain from a credit reporting body (CRB) a credit report containing personal credit information (e.g. name,address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) about the Client in relation to credit provided by SCJ.

  4. 19.4  The Client agrees that SCJ may exchange information about the Client with those credit providers and with related body corporates for the following purposes:

    1. (a)  to assess an application by the Client; and/or

    2. (b)  to notify other credit providers of a default by the Client; and/or

    3. (c)  to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit

      providers; and/or

    4. (d)  to assess the creditworthiness of the Client including the Client’s repayment history in the preceding two (2) years.

  5. 19.5  The Client consents to SCJ being given a consumer credit report to collect overdue payment on commercial credit.

  6. 19.6  The Client agrees that personal credit information provided may be used and retained by SCJ for the following purposes (and for other

    agreed purposes or required by):
    (a) the provision of Works; and/or
    (b) analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Works; and/or(c) processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or
    (d) enabling the collection of amounts outstanding in relation to the Works.

  7. 19.7  SCJ may give information about the Client to a CRB for the following purposes: (a) to obtain a consumer credit report;

(b) allow the CRB to create or maintain a credit information file about the Client including credit history.

  1. 19.8  The information given to the CRB may include:

    1. (a)  Personal Information as outlined in 19.3 above;

    2. (b)  name of the credit provider and that SCJ is a current credit provider to the Client;

    3. (c)  whether the credit provider is a licensee;

    4. (d)  type of consumer credit;

    5. (e)  details concerning the Client’s application for credit or commercial credit (e.g. date of commencement/termination of the credit account

      and the amount requested);

    6. (f)  advice of consumer credit defaults, overdue accounts, loan repayments or outstanding monies which are overdue by more than sixty

      (60) days and for which written notice for request of payment has been made and debt recovery action commenced or alternatively that the Client no longer has any overdue accounts and SCJ has been paid or otherwise discharged and all details surrounding that discharge(e.g. dates of payments);

    7. (g)  information that, in the opinion of SCJ, the Client has committed a serious credit infringement;

    8. (h)  advice that the amount of the Client’s overdue payment is equal to or more than one hundred and fifty dollars ($150).

  2. 19.9  The Client shall have the right to request (by e-mail) from SCJ:

    1. (a)  a copy of the Personal Information about the Client retained by SCJ and the right to request that SCJ correct any incorrect Personal Information; and

    2. (b)  that SCJ does not disclose any Personal Information about the Client for the purpose of direct marketing.

  3. 19.10  SCJ will destroy Personal Information upon the Client’s request (by e-mail) or if it is no longer required unless it is required in order to fulfil

    the obligations of this Contract or is required to be maintained and/or stored in accordance with the law.

#29014 © Copyright – EC Credit Control 1999 - 2019

Streamline Cabinets & Joinery Pty Ltd – Terms & Conditions of Trade

19.11 The Client can make a privacy complaint by contacting SCJ via e-mail. SCJ will respond to that complaint within seven (7) days of receipt and will take all reasonable steps to make a decision as to the complaint within thirty (30) days of receipt of the complaint. In the event that the Client is not satisfied with the resolution provided, the Client can make a complaint to the Information Commissioner at www.oaic.gov.au.

20. Building Industry Fairness (Security of Payment) Act 2017

  1. 20.1  At SCJ’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building Industry Fairness (Security of Payment) Act 2017 may apply.

  2. 20.2  Nothing in this contract is intended to have the effect of contracting out of any applicable provisions of the Building Industry Fairness (Security of Payment) Act 2017 of Queensland, except to the extent permitted by the Act where applicable.

21. Service of Notices

  1. 21.1  Any written notice given under this Contract shall be deemed to have been given and received:

    1. (a)  by handing the notice to the other party, in person;

    2. (b)  by leaving it at the address of the other party as stated in this Contract;

    3. (c)  by sending it by registered post to the address of the other party as stated in this Contract;

    4. (d)  if sent by facsimile transmission to the fax number of the other party as stated in this Contract (if any), on receipt of confirmation of the

      transmission;

    5. (e)  if sent by email to the other party’s last known email address.

  2. 21.2  Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.

22. Trusts

22.1 If the Client at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust (“Trust”) thenwhether or not SCJ may have notice of the Trust, the Client covenants with SCJ as follows:

  1. (a)  the Contract extends to all rights of indemnity which the Client now or subsequently may have against the Trust and the trust fund;

  2. (b)  the Client has full and complete power and authority under the Trust to enter into the Contract and the provisions of the Trust do not

    purport to exclude or take away the right of indemnity of the Client against the Trust or the trust fund. The Client will not release the right

    of indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity;

  3. (c)  the Client will not without consent in writing of SCJ (SCJ will not unreasonably withhold consent), cause, permit, or suffer to happen any

    of the following events:

(i) the removal, replacement or retirement of the Client as trustee of the Trust; (ii) any alteration to or variation of the terms of the Trust;
(iii) any advancement or distribution of capital of the Trust; or
(iv) any resettlement of the trust property.

23. General

  1. 23.1  The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.

  2. 23.2  These terms and conditions and any contract to which they apply shall be governed by the laws of Queensland, the state in which SCJ has its principal place of business, and are subject to the jurisdiction of the Brisbane Courts in that state.

  3. 23.3  Subject to clause 15, SCJ shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by SCJ of these terms and conditions (alternatively SCJ’s liability shallbe limited to damages which under no circumstances shall exceed the Price of the Works).

  4. 23.4  SCJ may licence and/or assign all or any part of its rights and/or obligations under this Contract without the Client’s consent.

  5. 23.5  The Client cannot licence or assign without the written approval of SCJ.

  6. 23.6  SCJ may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this Contract by so

    doing. Furthermore, the Client agrees and understands that they have no authority to give any instruction to any of SCJ’s sub-contractors

    without the authority of SCJ.

  7. 23.7  The Client agrees that SCJ may amend their general terms and conditions for subsequent future contracts with the Client by disclosing such

    to the Client in writing. These changes shall be deemed to take effect from the date on which the Client accepts such changes, or otherwise

    at such time as the Client makes a further request for SCJ to provide Works to the Client.

  8. 23.8  Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other

    event beyond the reasonable control of either party.

  9. 23.9  Both parties warrant that they have the power to enter into this Contract and have obtained all necessary authorisations to allow them to do

    so, they are not insolvent and that this Contract creates binding and valid legal obligations on them.

#29014 © Copyright – EC Credit Control 1999 - 2019